Time to terminate?

In today’s market, cash is a precious commodity. Many contractors and consultants in the UAE have overdue certified payment certificates and some have not been paid since last year.

So what do you do when payment from the employer is well overdue? How long must you fund a project before suspending or terminating your work? Can and should you terminate your contract? These are questions that many in the construction industry are facing today.

Understanding your contract’s suspension and termination provisions and relevant UAE law is paramount to protecting yourself from exposure to liability and preserving your rights to pursue claims for the money you are due.

It is always advisable to attempt to negotiate an acceptable payment plan with the employer before resorting to suspending or terminating a construction or consultancy contract.

Suspension and termination strain relationships create legal risks and uncertainty, and often lead to formal legal proceedings. If all else fails, however, suspension or termination may be the only remaining option.

Sometimes the mere act of serving a notice of intention to suspend or terminate is enough to prompt a resolution, and it never hurts to approach your client one last time before terminating.

Be aware of risks

You should consult your legal advisors before deciding on either course of action. If you do not follow the contract procedures carefully or otherwise suspend or terminate your contract improperly, you may be held responsible for delaying the project and exposing yourself to significant damages.

Read your contract in full and follow the procedures in the suspension or termination provisions exactly. Be certain that your notices are sent to the proper representatives designated in the contract.

Always keep proof of delivery of your notices. If you end up in legal proceedings, you will need evidence that you complied with the contract requirements.

Also, be aware of life safety issues and the protection of the works when winding down your site operation. As you demobilise, make every effort to minimise costs to yourself and the employer, and to cause minimal disruption to the project.

The Civil Code

So what does UAE law say about suspending or terminating a consultancy or construction contract? The Civil Code does not directly address a party’s right to suspend work, but it does provide that a party to a contract may refuse to perform its obligations, if the other contracting party does not perform its own obligations.

The Civil Code does directly address the termination of a construction contract. It states that construction contracts shall terminate upon the completion of the work agreed or upon the cancellation of the contract by consent or by order of the court. As a result, some may argue that a party to a construction contract may not unilaterally terminate the contract.

Another article of the code, however, permits parties to agree to a mechanism for termination when a party is in default, whereby one party may terminate its obligations without a judicial order upon the failure of the other party to perform its obligations. The code further provides that if one party does not do what it is obliged to do, the other party may, after giving notice to the obligor, require that the contract be cancelled.

To conclude

Suspension, and especially termination, should not be taken lightly, but sometimes they are necessary when you are not receiving payment and the prospect of future payment is uncertain. If done properly, you will have “stopped the bleeding” and won’t be incurring additional costs performing work, for which you are not being paid. In addition, you will have preserved your claims for payment.

Drew Baiter is a senior associate for Kilpatrick Stockton. He practices in the Dubai-based construction and infrastructure projects team where he advises clients, including employers, contractors and design professionals on construction projects throughout the UAE and the Mena region.

Print | Email | Discuss this article

| Share |

READERS' COMMENTS

contract
Posted by paul, Dubai, UAE on Monday 22 June 2009 at 14:35 UAE time


As mentioned, one can opt not to fulfill the obligations of a contract if the other party does not.

But as we have seen with many who bought property in Dubai, sometimes the contract is stacked in a very one-sided way, and enforced similarly. So one side can hike prices, change specs, fail to meet deadlines for starting work or delivery, and yet still demand payments on time.

So much comes down to the quality of the contract in place. A lot of small investors really signed very bad contracts that gave them no protection, and in many cases contracts they had not read before committing themselves with a deposit. I hope businesses were a bit smarter in this respect.

Time to terminate
Posted by Fredrick, Dubai, United Arab Emirates on Saturday 20 June 2009 at 16:30 UAE time


He is right in all aspect but not a single victim either contractor or consultancy never go to court in this region specially as you are not getting the correct judgment or some time they don't want to get black listed from the Employers. yes may be other part of the Globe they do.

Click here to post a comment

Add your Comment All posts are sent to the administrator for review and are published only after approval. ArabianBusiness.com reserves the right to remove any comment at any time for any reason. Please keep your responses appropriate and on topic. Arabian Business would like to point out that only comments relevant to the story will be published. Any containing personal insults or inappropriate language will not be approved.
Name *
Remember me on this computer
Email *	(Your email address will not be published)
City
Country
Subject *
Comment *
Notify me of further comments
Enter the words above *
Please click post only once - your comment will not be published immediately.

MORE FROM ARABIANBUSINESS.COM